Your preferred office location:
  1. Home
  2. /
  3. HHG Articles
  4. /
  5. HHG Construction Law Series Part 1: Contractors – Do you Understand Time Bars?
25 May 2016

A contractor gets paid an agreed price for delivery of an agreed scope of works by an agreed time.


That is of the essence of lump sum construction contracts.


However, it is virtually never the case that these three essential elements: scope, price and time, look the same at the end of the job as they did at the start.


Site instructions from the head contractor/principal will change the scope of the works; extension of time (EOT) claims will change the time for completion and variation orders will change the contract price.


Typically, under a lump sum construction contract, the head contractor/principal can instruct the contractor to do extra work and to omit certain parts of the original scope of works at any time.  The only limit is that the scope cannot be varied so much that the works as varied no longer look anything like the works under the original contract.  To take an extreme example, a principal cannot, by site instruction or variation (unless the contractor agrees), change timber works in a 3-storey apartment block into steelworks in a 10-storey apartment block because these are two completely different work scopes.


Outside of these extreme examples, the principal/head contractor will generally be free to vary the work scope, without needing the contractor to buy into the change, just by giving the direction to do extra work or omit some part of the work.  The contractor, however, is not so free to extend time or increase the contract price.  These rights are generally available under construction contracts but they are limited by time bars and procedural bars.


Time bars refer to the strict time limits that apply to EOT and price variation claims.  They are clauses in a construction contract that simply say, if you do not claim your EOT or price variation on time, then you cannot make that claim at all.  The effect of these time bars are strict and absolute.  This means that, no matter how much longer it takes you or how much more it costs you to do additional work as directed by the head contractor/principal, you do not get more time or more money to do that additional work if you do not make your claims within the time limits under the contract.


Procedural bars work the same way.  They basically say that an EOT or price variation will be claimed in a particular way under the contract and if you try and claim them in a different way, then your claim will be invalid.  Some contracts prescribe a particular form to be used in claiming EOTs/price variations.  If a form is prescribed, use it.  Some contracts prescribe specific information to be included in an EOT/price variation claim.  If specific information is prescribed, give it.


The courts have been unsympathetic to contractors who have missed out on their rights to claim more time and money because their claims were late or deficient under the contract.  This is one are where good, early legal advice is essential.  We can advise you about how to protect your rights when your head contractor/principal directs you to do more work than you bargained for and we can prepare the paperwork that you need to give on time and properly to make sure you don’t miss anything important.


This is general information only, and does not constitute specific legal advice. If you would like further information in relation to this matter or other legal matters please contact our office on Freecall 1800 609 945 or email us now.


*This is general information only, and does not constitute specific legal advice. Please consult one of our experienced Legal Team for specific advice relevant to your situation.

Supporting Western Australians for more than 100 years

"Always fast and thorough service. Thank you"


My circumstances at the time I made contact with HHG were dire following my argument being rejected by two no win no fee firms. Following my initial meeting with HHG's employment law team I was left feeling extremely positive by the response and concern shown by HHG in regards to their support of my argument along with their preparedness to pursue an outcome on my behalf.

I accept the fact that nobody really wins in these cases (mental health/ workplace) however the end result was what would be considered most favourable and far in excess of what would have been achieved had I not sought the advice from HHG.

I have no hesitation in recommending HHG to anyone caught up in the messy circumstances I found myself in at the time.

Great advice and five-star commitment to their client!!"


"Thank you for such great assistance with the transaction of Flying Domestics on behalf of Lorna Good. It has been such a pleasure to work with the HHG Legal Group and I look forward to working with you in the future."


"Simon Creek and his team were at all times empathic, professional and confident.  My matter needed to be addressed within a pressing time frame, and their availability at short notice and contact after hours was much appreciated.  It caused me considerable stress, but having such a thoroughly reliable and competent team to call on helped me to feel in control. Although I hope not to need their services again in future, I would be confident in doing so!"


"A good outcome is what we can expect.  A great outcome is a sign of a company which does the very best for their clients. A very big thank you to Daniel Morris for showing empathy towards my small and much needed legal action.

To HHG Legal Group, thank you for a great outcome.  I would recommend your company to anyone seeking legal services."


"Your support this morning was amazingly kind, not to mention your totally reassuring competence, knowledge and wisdom that you used on my behalf.  It was extremely reassuring to have your knowledgeable support, and I particularly appreciated your real and obvious kindness to me. It means so much at a very difficult time. I'm so grateful to you."

Family Law Client

"Janene was very professional and we established a good rapport quickly. The subject of death and wills can be quite confronting to deal with, however, Janene's approach was soft and accommodating."


"A big thank you to HHG for their professional service, continued support, and wide range of legal knowledge. Our clients have given us nothing but kind words regarding HHG Legal Group and so we have no hesitation in referring and recommending Simon Creek and HHG Legal Group for their outstanding services and legal expertise."


"Simon is a friendly and practical legal advisor. I have received great feedback from the clients I have referred to him and his team at HHG Legal Group."


"Over the last few years, I have been impressed by Simon’s legal ability, management skills, entrepreneurial spirit, personal integrity and people skills. He appears to be that rare breed of lawyer – both knowledgeable and commercial."


"Our family has been a client of HHG Legal Group over many years.  Business has included drawing up of wills for three generations and preparing of probate for my father in law. I would have no hesitation in recommending HHG Legal Group to anyone requiring such services."


"You should be congratulated for the manner in which your staff address clients and we found our dealings with your company, once again a very pleasant experience and we would like to truly thank you for your efforts."

Steve and Jane

"HHG Legal were absolutely fantastic. Extremely responsive and brought calm to our chaotic family situation through their knowledge and caring attitude. Extremely professional from our very first contact with them and they expertly guided our family though the required legal process over almost a 12 month period."


"Fantastic team! They really care about their client. Tim Colcutt is a 'go that extra mile' guy who gives his client his all. I can't recommend HHG and Tim enough."


"I had a fantastic lawyer in Matthew Lilly. He helped me out a great deal with good, sound advice in a friendly, professional manner. First class, thanks Matthew"


"Marine Plant Systems has been working with HHG Legal Group for a few years now and they continually provide first-class service. Their professional advice has been invaluable to our company."


"We were kept up to date at all times. Pricing was always updated over the time period so we remained "in budget". Personal access to someone whenever I had questions. All in all a great experience without too much fuss."


"Good service you can count on."


"HHG Legal Group has provided outstanding support as I have taken the journey of buying a business, their professionalism is beyond reproach. Their assistance throughout the Due Diligence process has been invaluable, I would fully recommend them."


"Very friendly and efficient service - what a pleasure working with Matthew."


"I highly recommend Daniel from HHG Lawyer in Mandurah. When dealing with a complicated legal property matter recently I was extremely impressed by Daniel's honesty and integrity and the legal advice I received. I am very happy with the service from HHG Legal."


Preferred Office location:

Please select your nearest office location so we can show you the most relevant information.